Court of Appeals of Kentucky, 1898

Geo. G. Fetter Printing Co. v. Courier-Journal Job Printing Co.

Geo. G. Fetter Printing Co. v. Courier-Journal Job Printing Co.
Court of Appeals of Kentucky · Decided October 1, 1898 · White
104 Ky. 381; 47 S.W. 241; 1898 Ky. LEXIS 166

Geo. G. Fetter Printing Co. v. Courier-Journal Job Printing Co.

Opinion of the Court

JUDGE WHITE

delivered the opinion of the court.

The appellant, the Geo. G. Fetter Printing Company, brought this action in the Jefferson Circuit Court, seeking an injunction restraining appellee, the Courier-Journal Job Printing Company, from completing certain work for the State of Kentucky under a contract made with the State commissioners of printing in 1893, to begin first Monday in January, 1894, and to continue two' years, said term having expired; also an injunction commanding appellee to turn over and deliver to appellant certain unfinished work, not then completed by appellee under the contract; and also asked judgment against appellee for $3,000 in damages on account of profits that appellant would necessarily have made on the work under the contract with the State; also an injunction is sought against S. H. Stone, Auditor of Public Accounts, to prevent said officer from issuing to appellee his warrant in payment for said work, if completed by appellee. There is filed with the petition an order as follows: “Frankfort, Ky., January 10,. ’96. To the Courier-Journal Job Printing Company, Louisville, Ky. — Gentlemen: You will *383turn over to the Geo. G. Fetter Printing Company all orders for printing of the first class on which work had not been begun January 6, 1896, and all unfinished work of the same class on hand at said date; your contract with the Commonwealth of Ky. having expired, and the contract of the Geo. G. Fetter Printing Company having come into force on that day. By order of the Board of Public Printing. Respectfully, Geo. W. Long, Secretary.” The petition alleges that the appellee had contracted with the Board of Public Printing, and that its contract had expired January 6, 1896, and that appellant had contracted with the board for the public printing of the first class for two years, beginning January 6, 1896; and it is alleged that notwithstanding the order of the Board of Public Printing as above stated, and of the expiration of appellee’s contract and the beginning of appellant’s contract, appellee had failed and refused to turn over to appellant certain work then unfinished and orders for work not begun. A demurrer by appellee to the petition was overruled, and answer was filed and proof was taken. After the proof was taken appellant filed an amended petition, and sought to recover damages of appellee in the sum of $5,282.77, with interest from that day, this being the amount of profit appellant claims it would have made on the work under the contract it had with the State. The injunction seems to have been abandoned, or, at least, not pressed. The court, on final hearing, dismissed the petition of appellant, and hence this appeal.

' The law governing the public printing of the State is found in sections 3942 to 3990, both inclusive, of Ky. Stats., and the sections applicable here are:

“Sec. 3955. The printing, paper, stationery and supplies necessary for the use of the State printing and binding *384specified in the first class, shall be furnished and paid for by the State, and the Commissioners of Public Printing of the State shall upon the requisition of the contractor from time to time, as the same may be needed, deliver over to the contractor suitable paper, stationery and supplies for the printing and binding which is required by his contract to do. The commissioners shall take and preserve from such contractor a receipt for all paper, and supplies' so delivered; and at the annual settlement on the first Monday in January, the contractor shall deliver to the Commissioners of Public Printing all paper and supplies so furnished by them, which has not been used in the State printing and binding; and if any such paper or supplies has been wasted or converted to any other use, the contractor to whom the same has been delivered shall be charged with the value thereof, together with penalty of fifty per cent, and the amount shall be deducted from his account.”
“Sec. 3987. The Secretary of State shall furnish a correct copy of the laws to the Printer thereof, and the clerks of the respective branches of the General Assembly shall each furnish to the Printer, who is bound by his contract to print the same, copies of the journals, bills, reports and other papers, documents and resolutions, without unnecessary delay.”
“Sec. 3988. The contractor for the printing and binding of the first class shall promptly and without delay, execute all orders of the General Assembly, or either branch thereof, for the printing of all bills, resolutions and other matter; and all contractors under the provisions of this act shall promptly and without unnecessary delay, execute all orders to them issued by the General Assembly *385or either branch thereof, or the executive officers of the State.”
“Sec. 3978. * * * Nor shall any composition, on any pretext whatever, be paid for a second time upon any report, document or publication, unless the work shall have been actually done, and only when unavoidable necessity compels its resetting.”

It is shown in the proof that on January 6, 1896, the day the contract of appellant begun and the day the contract of appellee expired, appellee had on hand, unfinished, a report of the Auditor, Railroad Commissioners, Superintendent of Public Instruction, and volume 96 of Kentucky Reports, in various states of progress, in some a comparatively few pages in type and in others partly printed; that after this action was brought the State Board' of Public Pointers permitted the appellee to complete all of this work, and accepted same from appellee, and paid for it under the contract with appellee. By section 3957, it is provided that the contract for public printing shall be let biennially, and for the period of two years, beginning- the first Monday in January. The pleadings show that appellee contracted for the printing of the first class for two years-, beginning first Monday in January, 1894, and ending first Monday in January, 1896. The General Assembly of the State met on Tuesday after the first Monday in January, and by section 155, Ky. Stats., it is provided that the report of the Auditor shall be presented to the Legislature on or before the sixth day of its session. By section 4389, Ky. Stats., it is provided that the report of the Superintendent of Public Instruction shall be made on or before ‘the meeting of the Legislature. By section S34 it is pro*386vided that the report of the Railroad Commissioners shall be printed and laid before the Legislature within the lirst ten days of its session. Section 8814 provides that the report of the penitentiary shall be printed for the Legislature. In view of these statutes, and the fact that the Legislature convened so soon after the expiration of one and the beginning of the other contract, it is perfectly apparent that it was in contemplation of the bidder in making the contract, and the board in awarding the contract to appellee understood, that all of this class of work would be done by appellee under its contract. By the proof it is shown that the executive officers delayed the work by not furnishing the manuscript earlier, and that as soon as the manuscript came to hand the work was begun in good faith by appellee, and# we are of opinion that appellee had a right, under its contract, to do this work, and to complete same after it had actually begun it in good faith. It is clear, by section 3978 quoted, that the State was not authorized to pay for resetting the matter in type that had been set in type by appellee at the expiration of its contract. In order that the State could not be called upon to pay for double composition, it was necessary, and a reasonable construction of the contract, and the law under which it was made, that appellee be allowed to complete its work on hand actually begun in good faith, but yet unfinished. Tt would thus follow that appellant could not recover.

We do not agree with counsel for appellant that the parties stood in the relation of an officer of the State- - Public Printer — but that the relation was one of contract. By section 3985, Ky. Stats., the office of Public Printer expired the first Monday in January, 1894, the day Hie eon- *387' tract of appellee begun. The rights of the parties are fixed by the contract and the law in force at the time of its execution. This view of the case renders it unnecessary for us to consider the other question presented by counsel and in the record. We perceive no error in the judgment, and the same is affirmed.

Case-law data current through December 31, 2025. Source: CourtListener bulk data.