This is a suit for $19,877.-09, balance due on a contract. The only defenses are two alleged offsets — one of $4,-559.60, and one of $1,126.23.

I.

Defendant contracted with the Hibernia Bank pf New Orleans to construct an office building, the nature and details of which contract are not in the record. Defendant sublet to plaintiff a contract to drive all the piling on which the foundations were to rest, and the pertinent articles of that subcontract are as follows:

“Article 1. The subcontractor [plaintiff] agrees to supply all the labor, piling and sheet piling, equipment and service to do all things necessary for the proper driving and completion of the work shown on plans and described in the specifications.

“Article 3. In consideration of the performance of the contract, the contractor [defendant] agrees to pay the subcontractor in current funds on the last day of each month, as compensation for his services, the actual .cost of the work, said actual cost to include the furnishing and driving of all piling and .sheet piling and, the necessary equipment to drive same, plus a fee of 8 per cent.

“The subcontractor, as one of the considerations of this contract, hereby guarantees that the total cost of said work will not exceed in actual cost.and fee as hereinabove stated the sum of $75,000.”

II.

As we have said, the nature of the contract between defendant and the bank is not before us; but the specifications provided as follows: ^

“The proposal for pile driving shall be based on using 50-foot piles. Should test piles show that proper resistance cannot be reached with 50-foot piles the contractor will be allowed - dollars ,extra per lineal foot additional.. Should proper resistance be reached with piles shorter than 50 feet, the contractor will allow a credit of-dollars per lineal foot for total number of lineal feet less-than required oh a 50-foot basis.”

III.

It will be seen at a glance that such a clause would be very pertinent in a contract for a lump sum or where the payment is to be by unit or piece, but can have no possible pertinency to a “cost plus” contract in which the work is to be done for actual cost plus a percentage "for profit, -except in so far as the. same might hear on a guarantee that the cost would not emceed a certain limit; since to purchase and drive longer piles would increase the cost.

Accordingly when the driving of test piles showed that 50 per cent, of the piles to be driven would exceed the 50-foot length, plaintiff wrote defendant as follows:

“I am writing to ask you to incorporate in the contract for piling a supplemental agreement as follows: ‘It is agreed and understood that, owing to the fact that the architects have determined that longer piles than 50 feet are required, an amount of 50 cents per lineal|foot for each foot over 50 feet, on all piles 53 feet, 55 feet and 60 feet long, he added to the guaranteed price." (Italics ours.)

IV.

There is evidence in the record showing that, at an interview between the architects and defendant, at which plaintiff was present, it was agreed that defendant should receive, on each pile driven, 50 cents per lineal foot for each foot over 50, and have 50 cents per lineal foot deducted for- each foot under that length. And it is pretended *488that this understanding was also to affect plaintiff’s contract, so that (in effect) though plaintiff was still to receive only actual cost (plus his percentage) there was to be deducted therefrom 50 cents per lineal foot for each foot less than 50, on each pile driven by Him.

Plaintiff denies that he had any such understanding, and it is simply incredible that any sane man would have agreed to any such proposition. Eor it is clear that by deducting 50 cents per foot on piling after receiving only actual cost (plus commission) he would simply be doing the work for 50 cents per lineal foot below cost. We do not think plaintiff entered into any such agreement, and defendant’s claim for 20 cents per lineal foot (cost of driving only) on 22,-798 feet is wholly without merit.

It is true that plaintiff himself once made a claim for extra compensation on the extra lengths, but he saw at once that his claim was untenable, and abandoned it before filing this suit.

V.

Defendant also seeks to offset $1,126.-23, being the amount expended to send a man out to hurry up the delivery of piles. This was done without the knowledge or consent of plaintiff, and f without putting him in default for any actual or anticipated delay in completing his contract. Doubtless defendant had reasons of its own for speeding ' the work, but we fail to see wherein plaintiff was in any way concerned therein except in so far as required to .complete his contract on time; and it is not pretended that he failed to do so.

Decree.

The judgment appealed from is therefore affirmed.