Hutchins v. Bautch
Hutchins v. Bautch
Opinion of the Court
Tbe ultimate question for solution in this case is, under the circumstances were respondents entitled .to a lien under ch. 143, Stats. 1898, the person they dealt with having, more than six months after their contract was, as regards appearances to third parties, performed, conveyed .her interest in the land to appellant? The errors assigned, in the main, are that the trial court improperly held that the ■ contract included the work of putting on the frost-proof cock; that putting it on after the apparent completion of the work, as regards third parties, extended the time for filing the lien petition; that an entry on the premises to complete the ivork after the sale to plaintiff, without his permission, could affect .the right of lien; and that the delay of one year in putting -on the frost-proof cock was according to custom, or was reasonable.
On all questions of fact involved in the assignments of .■error the evidence, as we find it in the record, is so conflicting that under familiar rules the trial court’s findings cannot properly be disturbed.
Counsel argue that the contract was so indefinite that, as ■a matter of law, the putting in of the frost-proof cock should not be deemed to be included therein. On that reference is •made by counsel to decisions elsewhere. There is nothing in .■our statutes suggesting as an essential to a lien on realty, as to third parties, that the terms of the contract must be so pre- ■ cise that the amount agreed to be paid for work and material furnished thereunder can be definitely determined therefrom. Lne rule in Massachusetts, which counsel invoke, does •not apply to our statutes. They in unequivocal terms provide that every person, who as principal contractor furnishes work or material in specified cases, including such as the one before us, used in the improvement of realty so as to become :a part thereof, is entitled to a lien for the indebtedness created thereby upon all the right, title and interest in such ;realty of the person contracted with at the time of the com
In support of the point that omission to furnish some unimportant part of contract work, or material, till a considerable period after the contract has been apparently fully performed cannot extend the time for filing the lien petition. Chapman v. Wadleigh, 33 Wis. 267, is referred to. That; case is to the- effect that the language of sec. 3314, Stats.. 1898, providing that the lien shall have priority over any other lien originating subsequent to the commencement of' the construction, repair, etc., calls for visible physical acts in that regard, likely to give notice to third parties dealing in respect to the realty and put them on inquiry. It has no reference to necessity for visible continuity of work from; the commencement thereof to the beginning of the period, limited for filing the lien. Fish Creek B. & L. D. Co. v. First Nat. Bank, 80 Wis. 630, 50 N. W. 585, cited by coun*-sel, relates to the log-lien statute, which expressly requires; continuity of work. Berry v. Turner, 45 Wis. 105, also-cited, is to the effect that work done after completion of a contract, pursuant to a settlement for breach thereof does not count in determining the time within which the’ lien may be-filed for indebtedness accruing under the contract. Numer
It seems that counsel are in error in their position that the trial court decided that a lien can be acquired, or the time for filing a lien petition extended, by the commission of a trespass. When the last act under the contract was performed the person respondents contracted with was still in possession of the premises, and so far as we can discover, neither she nor any one else prohibited them from completing their work. 'The trial court, doubtless, found that there was no such prohibition, and that if it were otherwise, their willingness to complete their work was sufficient to save their right of lieu for work already done. It may be that if one sell land while lienable work is in progress thereon under a contract, the license incident to the contract to enter upon the premises might be terminated by the new owner, but he could not by any mere act of his defeat the lien remedy of the contractor for work already done. If he refused to allow completion of the contract an offer to do so would be equivalent to performance, as regards the commencement of the time limited by law for filing the lien petition for Avork and material already furnished. Otherwise the remedy under the lien statute might in many cases be defeated by sale of the realty pending the execution of a contract to do lienable Avork thereon.
There are no other questions suggested for consideration deemed to be of sufficient importance to call for special treatment.
'By the Gourt. — The judgment is affirmed.
Reference
- Full Case Name
- Hutchins v. Bautch and another
- Cited By
- 7 cases
- Status
- Published
- Syllabus
- Appeal and error: Findings, when disturbed: Oonclusiveness: Mechanics’ Hens: Contracts: Definiteness: Continuity of worh:\\ Estoppel: Sale of land pending doing of lienable work: Offer to perform. 1. Findings of fact made hy a trial court are to he deemed verities in support of the judgment rendered thereon, unless from the-record it appears that they are contrary to the clear preponderance of the evidence. 2. It is not an essential under the lien remedy given to mechanics and materialmen hy ch. 143, Stats. 1898, that the, contract for furnishing the labor or material should be so definite as to enable the one personally liable to the lien claimants, or the owner or person interested in the structure involved, to determine precisely the contract price for such labor or material or the details of the work. It is sufficient as to work or material alleged to have been furnished under one contract to show that it was in fact so furnished. 3. While there must be some visible commencement of work under the lien statute to fix the time of the commencement of the lien claim, there need not be visible continuity of work from first to last in order that the last labor or material furnished may relate back to the commencement of work, and all be-regarded as furnished under one contract or an entire running account. 4. Delay in completing lienable contract work sufficient to indicate-so clearly either that the contract has been fully performed or has been abandoned, as to excuse third parties dealing with the property from making inquiries in respect to the matter,, may affect the right of lien upon principles of estoppel in pais. 5. If, while a person is in the performance of lienable work on .land under contract with the owner the latter sells the land' to a third party, such person is in any event entitled to a lien thereon for the work and material already furnished whether •he completes his contract or not, if failure in that regard is without fault on his part. An offer by him to perform, as regards preservation of his lien, is equivalent to performance. [Syllabus by Marshall, J.]